[{"data":1,"prerenderedAt":-1},["ShallowReactive",2],{"doc-seo-339225-105":3,"detail-sidebar-cat-1-en-105":80,"doc-detail-339225-en":126},{"code":4,"msg":5,"data":6},0,"ok",{"site_id":7,"language":8,"slug":9,"title":10,"keywords":11,"description":12,"schema_data":13,"social_meta":73,"head_meta":75,"extra_data":77,"updated_unix":79},105,"en","residential-roofing-contract-free-form","Residential Roofing Contract - Free Form","","Residential Roofing Contract form defining terms between a customer and a contractor for roof-related work. It covers the contract documents structure, scope of work and work hours, commencement and completion requirements including substantial completion criteria, delay handling and time extensions, liquidated damages, and conditions for cancellation if permits cannot be obtained. It also specifies contract price calculation options and payment schedules, including tax treatment, interest on late payments, and rules for payments only to the contractor.",{"@graph":14,"@context":72},[15,34,55],{"@type":16,"itemListElement":17},"BreadcrumbList",[18,23,27,31],{"item":19,"name":20,"@type":21,"position":22},"https://docshare.wps.com","Home","ListItem",1,{"item":24,"name":25,"@type":21,"position":26},"https://docshare.wps.com/template/","Template",2,{"item":28,"name":29,"@type":21,"position":30},"https://docshare.wps.com/template/forms/","Forms",3,{"item":32,"name":10,"@type":21,"position":33},"https://docshare.wps.com/template/residential-roofing-contract-free-form/339225/",4,{"url":32,"name":10,"@type":35,"image":36,"author":41,"headline":10,"publisher":44,"fileFormat":47,"inLanguage":8,"description":12,"dateModified":48,"datePublished":49,"encodingFormat":47,"isAccessibleForFree":50,"interactionStatistic":51},"DigitalDocument",{"url":37,"@type":38,"width":39,"height":40},"https://docshare.wps.com/thumbnails/residential-roofing-contract-free-form/339225.png","ImageObject",442,249,{"name":42,"@type":43},"wps_ap_test_251126_0180","Person",{"url":19,"name":45,"@type":46},"DocShare","Organization","application/pdf","2026-09-27","2026-09-21",true,{"@type":52,"interactionType":53,"userInteractionCount":30},"InteractionCounter",{"@type":54},"ViewAction",{"@type":56,"mainEntity":57},"FAQPage",[58,64,68],{"name":59,"@type":60,"acceptedAnswer":61},"What documents are considered part of the contract under this form?","Question",{"text":62,"@type":63},"The contract documents include the contract itself with drawings, specifications, schedules, addenda, or exhibits, plus additional documents signed by both parties during the contract term.","Answer",{"name":65,"@type":60,"acceptedAnswer":66},"How does the contract handle delays in completing the work?",{"text":67,"@type":63},"If delays are caused by customer actions, other contractors, ordered changes, weather, labor disputes, fire, unusual carrier delays, unavoidable casualties, arbitration, or other causes beyond the contractor’s control, the completion time is extended by the delay period.",{"name":69,"@type":60,"acceptedAnswer":70},"What payment terms options does the contract provide?",{"text":71,"@type":63},"The contract price can be set as an all-inclusive fixed cost, a cost plus percentage of cost, or a cost plus a fixed amount, each with specified payment timing and balance due upon work completion.","https://schema.org",{"og:url":32,"og:type":74,"og:title":10,"og:site_name":45,"og:description":12},"article",{"robots":76,"canonical":32},"index,follow",{"doc_id":78,"site_id":7},339225,1790468255,{"code":4,"msg":81,"data":82},"success",[83,88,93,98,103,108,112,117,122],{"id":84,"doc_module":22,"doc_module_name":25,"category_name":85,"show_sort_weight":86,"slug":87},11,"Presentations",90,"presentations",{"id":89,"doc_module":22,"doc_module_name":25,"category_name":90,"show_sort_weight":91,"slug":92},12,"Resumes",80,"resumes",{"id":94,"doc_module":22,"doc_module_name":25,"category_name":95,"show_sort_weight":96,"slug":97},14,"Invoices",70,"invoices",{"id":99,"doc_module":22,"doc_module_name":25,"category_name":100,"show_sort_weight":101,"slug":102},15,"Posters",60,"posters",{"id":104,"doc_module":22,"doc_module_name":25,"category_name":105,"show_sort_weight":106,"slug":107},16,"Social Media",50,"social-media",{"id":109,"doc_module":22,"doc_module_name":25,"category_name":29,"show_sort_weight":110,"slug":111},17,40,"forms",{"id":113,"doc_module":22,"doc_module_name":25,"category_name":114,"show_sort_weight":115,"slug":116},18,"Letters",30,"letters",{"id":118,"doc_module":22,"doc_module_name":25,"category_name":119,"show_sort_weight":120,"slug":121},21,"Paper Templates",5,"papers-templates",{"id":123,"doc_module":22,"doc_module_name":25,"category_name":124,"show_sort_weight":4,"slug":125},158,"General","general-158",{"code":4,"msg":81,"data":127},{"doc_id":78,"user_id":128,"nickname":42,"user_avatar":129,"doc_module":22,"category_id":109,"category_name":29,"doc_title":10,"doc_description":12,"doc_content":130,"file_id":131,"file_url":132,"file_type":133,"file_size":134,"view_count":30,"is_deleted":4,"is_public":22,"is_downloadable":22,"audit_status":22,"page_count":30,"language":135,"language_code":8,"site_id":7,"html_lang":8,"table_of_contents":136,"faqs":137,"seo_title":138,"seo_description":12,"update_tm":139,"read_time":22},8796095027276,"https://avatar.qwps.com/avatar/d3BzX2FwX3Rlc3RfMjUxMTI2XzAxODA=","RESIDENTIAL ROOFING CONTRACT  \nCUSTOMER:  \n\n| Name: |  |  |  |\n| --- | --- | --- | --- |\n| Contact Person (if customer is a business): |  |  |  |\n| Billing Address: |  |  |  |\n| Business Phone: |  | Fax Number: |  |\n| Cell Phone: |  | Home Phone: |  |\n| Email: |  |  |  |\n| Project Address (if different from the above): |  |  |  |\n\nIn consideration of the payments to be made by Customer to [NAME OF CONTRACTOR] (the\"Contractor\"), whose address is   [address of contractor] the parties hereby agree as follows:  \n1. Contract Documents. The Contract Documents, taken together, shall constitute the entire agreement between the parties pertaining to the subject matter hereof and supersede all other agreements, understandings, negotiations and discussions, whether oral or written, of the parties and there are no warranties, representations or agreements between the parties in connection with the subject matter of the Contract Documents except as specifically set forth therein. The Contract Documents consist of the following:  \n(a) this Contract and any drawings, specifications, schedules, addenda or exhibits attached to this Contract;  \n(b) additional documents signed by both parties during the course of this Contract. (Extras, amendments and deletions are effective ONLY if documented on a Change Order form or other amending agreement in writing and initialed or signed by both parties); and  \n(c)    \nDiscrepancies or omissions in the Contract Documents, site conditions and any work requested in variance of the Contract Documents are considered an extra to the Contract and are not included in the Contract Price. Any additional work required due to site conditions not disclosed to Contractor, or which could not be reasonably anticipated, are not included in the Contract Price and shall be an extra to the Contract Price.  \n2. Description of Work. Contractor agrees to provide all materials, labor, tools, equipment and supervision required to perform the Work (\"Work\") set out in the attached Work Schedule, in accordance with the Contract Documents. The Work will be performed between the hours of   a.m. and   p.m., Monday through Saturday, statutory holidays excluded, unless the parties mutually agree, provided that the Work will be performed only if weather conditions are favorable, in order to ensure an acceptable finished product.  \n3. Commencement Date & Completion Date. Contractor will commence the Work on or before   (“Commencement Date”) . Contractor agrees that the Work shall be completed no later than   (“Completion Date”), with substantial completion on or before   .“Substantial completion”means that the Work has been completed (a) to the degree specified for substantial completion or substantial performance under any applicable [State/provincial]  \nlaws; (b) to the point where the project site is ready for use for the intended purpose, and (iii) to the point where an occupancy permit (where the same is required) has been issued.  \n4. Delays. If Contractor is delayed in the completion of the Work by any act or neglect of Customer, or by any other contractor employed by Customer, by changes ordered in the Work, weather conditions, strikes, lockouts, fire, unusual delay by common carriers, unavoidable casualties, pending arbitration or any other cause beyond Contractor's control, then the time of completion of the Work as set out in paragraph 3 above shall be extended for a period equal to the period of delay of any or all of the abovestated causes. Customer shall have no obligation to grant an extension of time if any delay in completion of the Work was caused, directly or indirectly, from Contractor’s breach of this Contract. In the event the Work is delayed due to neglect of Contractor, Contractor agrees to pay the Customer the sum of $\\#\\#\\#.\\#\\# per day as liquidated damages until such time as the Work is completed. In the event of a delay, Contractor must inform Customer as soon as possible of the occurrence of a delay, the reas","cbCaitiwazww7LtH","https://ap.wps.com/l/cbCaitiwazww7LtH","pdf",91248,"English","# Customer and Parties\n## Project details\n# Contract Documents\n## Included documents\n# Description of Work\n## Schedule and hours\n# Commencement and Completion\n## Substantial completion\n# Delays\n## Extensions, liquidated damages, cancellation\n# Contract Price and Payment Terms\n## Fixed cost or cost-plus options","[{\"question\":\"What documents are considered part of the contract under this form?\",\"answer\":\"The contract documents include the contract itself with drawings, specifications, schedules, addenda, or exhibits, plus additional documents signed by both parties during the contract term.\"},{\"question\":\"How does the contract handle delays in completing the work?\",\"answer\":\"If delays are caused by customer actions, other contractors, ordered changes, weather, labor disputes, fire, unusual carrier delays, unavoidable casualties, arbitration, or other causes beyond the contractor’s control, the completion time is extended by the delay period.\"},{\"question\":\"What payment terms options does the contract provide?\",\"answer\":\"The contract price can be set as an all-inclusive fixed cost, a cost plus percentage of cost, or a cost plus a fixed amount, each with specified payment timing and balance due upon work completion.\"}]","Residential Roofing Contract - Free Form | PDF",1790028823]